Terms of Service

1. Agreement to Terms

By accessing or using the services of Swift Intercom Pty Ltd ("Company," "we," "us," or "our"), you agree to be bound by these Terms of Service. If you do not agree to these terms, please do not use our services.

2. Services Description

Swift Intercom provides telecommunications and IT infrastructure services including but not limited to: fiber optic installation, IT infrastructure solutions, security systems installation, BTS installation, site surveys, and equipment supply. All services are subject to separate service agreements and quotes.

3. Quotes and Proposals

All quotes and proposals provided by us are valid for 30 days unless otherwise stated. Prices are subject to change based on:

• Changes in project scope or requirements
• Site conditions not disclosed during quoting
• Equipment availability and pricing fluctuations
• Regulatory or compliance requirement changes

4. Project Execution

Project timelines are estimates based on information available at the time of quoting. We will:

• Provide estimated start and completion dates
• Communicate any delays as soon as practicable
• Require client cooperation for site access and approvals
• Not be liable for delays caused by factors outside our reasonable control

5. Payment Terms

Payment terms are as specified in individual service agreements. Generally, we require:

• A deposit before project commencement
• Progress payments as milestones are achieved
• Final payment upon project completion and acceptance
• Payment within 14 days of invoice date

6. Warranties

We warrant that our services will be performed in a professional and workmanlike manner. Equipment warranties are as provided by the manufacturers. Our workmanship warranty period is 12 months from project completion unless otherwise specified.

7. Limitation of Liability

To the maximum extent permitted by Australian law, our liability for any claim relating to our services is limited to the amount paid for the specific service giving rise to the liability. We are not liable for indirect, consequential, or incidental damages.

8. Intellectual Property

All designs, documentation, and materials created by us remain our intellectual property until full payment is received. Upon payment, clients receive a license to use documentation for the specific project purpose.

9. Governing Law

These Terms are governed by the laws of New South Wales, Australia. Any disputes shall be subject to the exclusive jurisdiction of the courts of New South Wales.

10. Contact Information

For questions about these Terms, please contact us:

Swift Intercom Pty Ltd
Level 12, 100 Miller Street
North Sydney, NSW 2060
Email: legal@swiftintercom.com
Phone: +61 2 9123 4567